[2011] 15 (ADDL.) S.C.R 1129 PHULCHAND EXPORTS LTD. A v. 000 PATRIOT (CIVIL APPEAL NO. 3343 OF 2005) OCTOBER 12, 2011 B [R.M. LODHA AND JAGDISH SINGH KHEHAR, JJ.]

Arbitration and Conciliation Act, 1996 - ss.47 and 48 -Enforcement of award - Test of principles of public policy -C/F Contract - The appellant-sellers shipped goods and the c vessel freighted by the sellers left the port of loading viz. Kand/a, India - The vessel carrying the goods, however, suffered engine failure and consequently the goods did not reach the port of destination (port of Novorossiysk, Russia) -The respondent-buyers lodged recovery claim against the 0sellers before the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of the Russian Federation, Moscow - The said Arbitral Tribunal held that there were breaches by the sellers and that the clause for reimbursement could be invoked by the buyers -The Arbitral Tribunal, however, did not award the full price paid E by the buyers to the sellers but instead awarded /Jalf of that amount as there was delay by the buyers in invoking the clause of reimbursement [clause 4 of the contract] and the buyers also did not pass the shipping documents and the insurance certificate to the sellers - Arbitration petition filed F by respondent-buyers for enforcement of the award - Allowed by High Court - Whether enforcement of the award in favour of the respondent was contrary to public policy of India under s.48(2)(b) of the Act - Held: The appellant-sellers breached the terms of the contract at the very threshold by late shipment G of goods and by loading on board the vessel which was no longer to reach the port of Novorossiysk as the first port of discharge - The sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods 1129 H

1130 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A can be held to have resulted in postponement of transfer of title in goods to the buyers - Even if the property in the goods was deemed to have transferred to the buyers, since there was no delivery of the goods due to the fault of the sellers in shipment of the goods, the goods continued to be at the risk B of the sellers - In that situation, first proviso to Section 26 of the 1930 Act was clearly attracted - No merit in the case set up by the sellers that their liability ceased to exist on shipment of the goods or in any case when the shipping documents were handed over through the banking channels on negotiations of Letter of Credit - Stipulation for C reimbursement in the event stated in clause 4 of the contract was not in the nature of penalty; the clause was not in terrorem

- It was neither punitive nor vindictive - No reason why the sellers should not be bound by it and the court should not enforce such term - The sellers and the buyers in the present D case were business persons having no unequal bargaining ppwers - Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein was neither unreasonable nor unjust; far from being extravagant or unconscionable - It was E the precise sum which the sellers were required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time -More so, the fact of the matter was that goods never arrived at the port of,discharge - The Arbitral Tribunal only awarded F reimbursement of half the· price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary to the public policy of India - Sale of Goods Act, 1930 - s.26 - Contract Act, 1872 - ss.23, 73 and 74. G Arbitration and Conciliation Act, 1996 - s.48(2)(b) -Expression 'public policy of India' used in s.48(2)(b) - Held: Has "to be given wider meaning - Arbitral award can be set aside, 'if it is patently illegal'.

Contract- CIF contract- Obligations upon a seller under H a C.J.F. contract - Held: In relation to goods, the seller must PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1131 ship goods of contract description on board a ship bound to A the contract destination - If there is a late shipment or the seller has put goods on board a ship not bound to the contract destination as stipulated, the logical inference that must necessarily follow is that the seller has not put on board goods conforming to a contract destination. B Transaction relating to sale of 1000 Metric Tons of Indian long grain polished rice for a price fixed at INR 12,450 (Indian Rupees twelve thousand four hundred fifty only) per one metric ton net on CIF (liner out) Novoross.iysk, Russia basis was concluded, vide a c contract between the appellant-sellers and respondent-buyers. The appellant-sellers shipped goods - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of loading viz., Kandla (India) - 38 days later than the time of departure stipulated in the contract. The goods, however, never reached the port of D destination (port of Novorossiysk) inasmuch as the vessel carrying the goods suffered an engine failure and in salvage operation, the vessel was taken to the Turkish sea port of Eregli where the concerned Admiralty court took judgment to arrest vessel towards the cost of rescue E and the entire cargo was sold out to compensate the cost of rescue of the vessel.

The respondent-buyers lodged claim against the sellers for recovery of amount in the International Court of Commercial Arbitration at the Chamber of Commerce F and Industry of the Russian Federation (for short "the Arbitral Tribunal"). The buyers' claim was founded on the breach of contract by the sellers and particularly with reference to clause 4 of the contract that provided, "in case the goods do not arrive to the customs area of G Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the buyers' account". The Arbitral Tribunal held that there were breaches by the sellers and that the clause for reimbursement H 1132 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A could be invoked by the buyers. The Arbitral Tribunal, however, did not award the full price paid by the buyers to the sellers but instead awarded half of that amount as there was delay by the buyers in invoking the clause of reimbursement and the buyers also did not pass the shipping documents and the insurance certificate to the 8 sellers. The buyers filed Arbitration Petition under Sections 47 and 48 of the Arbitration and Conciliation Act 1996 for enforcement of the above award. The sellers contested C the petition on the ground that subject award was contrary to the principles of public policy and, therefore, the award was unenforceable. A Single Judge of the High Court over-ruled the objections raised by sellers and held that the award could be enforced as a decree of the Court. The Division Bench relying upon the decision of D this Court in Renusagar Power held that award was purely based on findings of facts and no public policy was involved and upheld the order of the Single Judge. The question which arose for consideration in the E instant appeal was whether enforcement of the award given by the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of Russian Federation, Moscow in favour of the respondent was contrary to public policy of India under Section 48(2){b) of the Arbitration and Conciliation Act, 1996. F Dismissing the appeal, the Court HELD:1. In Renusagar Power case (as relied upon by the Division Bench of the High Court), a narrower meaning had been given to the expression 'public policy G of India' while this Court in a subsequent decision in the case of Saw Pipes Ltd. has given wider meaning to that expression. In view of the decision in Saw Pipes Ltd., the expression 'public policy of India' used in Section 48(2){b) has to be given wider meaning and the award could be H set aside, 'if it is patently illegal'. [Paras 12, 13] [1145-A-B: 1146-AJ

PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1133 Renusagar Power Co. Ltd vs. General Electric Co. AIR A 1994 SC 860: 1993 (3) Suppl. SCR 22; Oil and Natural Gas Corporation Ltd. vs. Saw Pipes Ltd. (2003) 5 SCC 705: 2003 (3) SCR 691 - referred to. 2.1. The title of Section 26 of the Sale of Goods Act, 1930 shows that the rule provided there-under is the B prima facie rule subject to the agreement otherwise between the parties. This is clearly indicated by the expression "unless otherwise agreed" with which the section begins. The parties to the contract are, thus, free to by-pass the prima facie rule provided in Section 26 by c making agreement otherwise. The prima facie rule in Section 26 is that the goods remain at the seller's risk until the property in the goods is transferred to the buyer. But when the property in the goods is transferred to the buyer the goods are at the buyer's risk whether delivery 0 has been made or not. The above rule has some exceptions. The first proviso provides that where delivery of goods has been delayed due to the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault. The second proviso is further subject E to the first proviso and provides that nothing in the section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the other party. [Para 20] [1148-H; 1149-A·D]

2.2. The obligations upon a seller under a C.l.F. F contract are well known, some of which are in relation to goods and some of which are in relation to documents. In relation to goods, the seller must ship goods of contract description on board a ship bound to the contract destination. If there is a late shipment or the G seller has put goods on board a ship not bound to the contract destination as stipulated, the logical Inference that must necessarily follow is that the seller has not put . on board goods conforming to a contract destination. [Para 21] [1149-E-F] H 1134 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A 2.3. In the present case, there was late shipment of goods by 16 days. Besides delay in shipping the goods and the delayed departure of the vessel from the port of loading, the goods were shipped in a vessel having no firm commitment to reach the port of Novorossiysk as the B first port of discharge. As a matter of fact, the sellers gave a line bill of lading giving a carrier right to determine the line of unloading ancf the consecutive order of '.lestinatioo "l>f sea ports and as a result of that the goods were loaded on board the vessel that was no longer to C reach the port of Novorossiysk as first port of discharge. The contract between the parties clearly provided in clause 4 that shipment should be done by a vessel that is on way to Novorossiysk as the first port of discharge. This term in the contract is not inconsequential or immaterial but seems to be fundamental having regard to D the subject matter of the goods. The sellers breached the terms of the contract at the very threshold by late shipment of goods and by loading on board the vessel which was no longer to reach the port of Novorossiysk as the first port of discharge. The sellers having breached E the terms of the C.1.F. contract at the threshold, it is very difficult to hold that property in the goods got transferred out and out to the buyers on shipment of the goods or when the shipping documents were handed over to the bank for negotiations of UC. In a case such as this one, F the sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods can be held to have resulted in postponement of transfer of title in goods to the buyers. In any case the prima facie rule contemplated in Section 26 of the 1930 Act stands rebutted in the facts of the present case. [Para 22) [1149· G G-H; 1150-A-D]

2.4. Even if the property in the goods is deemed to have transferred to the buyers, since there was no delivery of the goods due to the fault of the sellers in shipment of the goods, firstly belatedly and then by a H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1135 vessel that was not on way to Novorossiysk as the first A port of discharge, the goods continued to be at the risk of the sellers as they were in fault. In that situation, first proviso to Section 26 of the 1930 Act is clearly attracted. [Para 23] [1150-E-F] 2.5. There is no merit in the case set up by the sellers B that their liability ceased to exist on shipment of the goods or in any case when the shipping documents were handed over through the banking channels on negotiations of Letter of Credit. As in the present case, the sellers were in breach at the threshold, it is immaterial c whether or not the buyers had a right of action against the insurers or carrier. [Para 24] [1150-G] Johnson v. Taylor Bros. [1920] A.C. 144 - referred to. Lord Elphinstone vs. The Monk/and Iron and Coal Company Limited and Liquidators 1886 House of Lords D VOL. XI page 332 and Dunlop Pneumatic Tyre Company Limited vs. New Garage and Motor Company Limited (1915) AC 79 [House of Lords] - cited. Kennedy's CIF contracts (Third edition) revised by E Dennis C. Thompson and CIF and FOB Contracts (Fourth edition) by David M. Sassoon - referred to.

3.1. Section 73 of the Contract Act, 1872 provides for compensation for loss or damage caused by breach of contract and Section 74 makes a provision for F compensation for breach of contract where penalty is stipulated for. Both these Sections provide for reasonable compensation in a case of breach of contract. None of these two Sections makes the award of liquidated damages illegal. The plain reading of Section 74 would G show that it deals with the measure of damages in two classes of cases (i) where the contract names a sum to be paid in case of breach and (ii) where the contract contains any other stipulation by way of penalty. [Paras 26, 27 and 28] [1151-E-F; 1153-A-D] H 1136 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A 3.2. The stipulation for reimbursement in the event stated in clause 4 of the contract is not in the nature of penalty; the clause is not in terrorem. It is neither punitive nor vindictive. Moreover, what has been provided in the contract is the reimbursement of the price of the goods paid by the buyers to the sellers. The clause of8 reimbursement or repayment in the event of delayed delivery/arrival or non-delivery is not to be regarded as damages. Even in the absence of such clause, where the seller has breached his obligations at threshold, the buyer is entitled to the return of the price paid and for damages. C There is no reason why the sellers should not be bound by it and the court should not enforce such term. No way the clause is in the nature of threat held over the sellers in terror. [Para 29) [1154-B-E]

3.3. The transactions covered by Section 23 of the D 1872 Act are the transactions where the consideration or · object of such transaction is forbidden by law or the transaction is of such a nature that if permitted would defeat the provisions of any law or the transaction is fraudulent or the transaction involves or implies injury to E the person or property of another or where the court regards it immoral or opposed to public policy. Whether particular transaction is contrary to a public policy would ordinarily depend upon the nature of transaction. Where experienced businessmen are involved in a commercial F contract and the parties are not of unequal bargaining power, the agreed terms must ordinarily be respected as the parties may be taken to have had regard to the matters known to them. The sellers and the buyers in the present case are business persons having no unequal G bargaining powers. They agreed on all terms of the contract being in conformity with the international trade and commerce. Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein is neither unreasonable nor unjust; far from being extravagant or H

PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1137 unconscionable. It is the precise sum which the sellers A are required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time. More so, the fact of the matter is that goods never arrived at the port of discharge. The Arbitral Tribunal has only awarded B reimbursement of half the price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary to the public policy of India. [Para 31] [1155-C-H] Mau/a Bux vs. Union of India 1969 (2) SCC 554: 1970 c (1) SCR 928; Fateh Chand v. Balkishan Dass (1964) 1 SCR 515- referred to. Case Law Reference: 1993 (3) Suppl. SCR 22 referred to Paras 10,11, j2, D 2003 (3) SCR 691 referred to Para 11 1970 (1) SCR 928 referred to Para 14 1886 House of Lords VOL. Xlcited Para 15 (1915) AC 79 cited Para 15 E [1920] A.C. 144 referred to Para 18 (1964) 1 SCR 515 referred to Para 27 CIVIL APPELLATE JURISDICTION : Civil Appeal No. 3343 of 2005. . F From the Judgment & Order dated 3.5.2002 of the Bombay High Court in Appeal No. 4 of 2002 in Arbitration Petition No. 66 of 2001. Krishnan Venugopal, Kamal Budhiraja and Manu Seshadri G (for Dua Associates) for the Appellant. The Judgment of the Court was delivered by R.M. LODHA, J. 1. This appeal, by special leave, occupied judicial time of almost whole day, and the basic H

1138 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A question raised is this : whether enforcement of the award dated October 18, 1999 given by the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of Russian Federation, Moscow in favour of the respondent is contrary to public policy of India under Section B 48(2)(b) of the Arbitration and Conciliation Act, 1996.

2. By contract dated November 18, 1997, between -Phulchand Exports Limited, Mumbai, India ('the sellers') and 000 Patriot, Moscow, Russia ('the buyers'), a transaction relating to sale of 1000 Metric Tons of Indian long grain 1.5 time c polished rice PR-106 of 9 per cent broken maximum (for short, 'the goods') for a price fixed at INR 12,450 (Indian Rupees twelve thousand four hundred fifty only) per one metric ton net on CIF (liner out) Novorossiysk, Russia basis was concluded. The price was fixed according to lncoterms-90 and included value of the goods, packing and marl<ing, loading into hold,0 stowing of the cargo, fulfilling the customs formalities in the sellers' country, insurance, freight charges, berthing charges and unloading charges of the goods at the port of Novorossiysk. The total value of the contract was firm and fixed at INR 12,450,000,00 (Indian Rupees twelve million four hundred fifty E thousand only). It is upon this contract, and on what was done under it, that the above question in this appeal turns. Some of the relevant terms, and, omitting clauses which do not appear important, are as follows : "1. SUBJECT OF CONTRACT : F ............. the Goods on CIF Novorossiysk port, Russia basis, ......... . 2. PRICE OF THE CONTRACT ......... The price is fixed on the terms of CIF (liner out) G Novorossiysk, Russia according to lncoterms-90 ........ . 3. TERMS OF PAYMENT

Payment for the Goods, delivered under the present contract is to be effected by irrevocable documentary H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1139 [R.M. LODHA, J.] Letter of Credit opened in favour of the sellers for the total A value of the contract for the period of 45 days ............ . The L/C is governed by "ICC Uniform customs and practice for documentary UC" .......... . The L/C should be opened within 10 working days from B the date of signing of the contract. The L/C is executed by the beneficiary's bank against presentation by the sellers of the following documents: xxxxxxxx 3. Insurance Policy for 11 % of the value of the Goods, C Covering all risks stipulated in the Institute Cargo Clauses (A), Institute War Clauses, Institute Strike Clauses till the completion of the unloading of !he Goods at the port of Novorossiysk, issued in the name of the Buyers Bank - Joint Stock Commercial D Bank AVTOBANK, Moscow, Russia. xxxxxxx 4. TERMS OF DELIVERY

Shipment should be done on the basis of CIF (liner out) E Novorossiysk, Russia in accordance with lncoterms - 90. The Goods sold under the present contract should be shipped within 40 days from the date of opening the UC. The date of shipment is the date of loading of the Goods F to the board of vessel. ............... . Shipment should be done by a vessel that is on the way to Novorossiysk as the first port of discharge. The Sellers shall take all possible measures that transit time of the Goods to Novorossiysk, Russia will not exceed 25 days. G xxxxxxxxx The sellers shall take all possible measures for placing the Goods in such a way that it will be free for examination and will not be blocked up by any other cargo while unloading at the port of Novorossiysk... ... . . . . H 1140 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A Insurance Policy for 110% of the value of the Goods, covering all risks, stipulated in the Institute Cargo Clauses (A), Institute War Clauses, Institute Strike Clauses till the completion of the unloading of the Goods at ~he port of Novorossiysk, issued in the name of the Buy~rs Bank -Joint Stock Commercial Bank AVTOBANK ......... .B xxxxxxxx In case the Goods do not arrive to the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the C Buyers' account. 8. PENALTY

The Sellers are obliged within 5 working days from the <;late of receipt of the Buyers advice of the UC to open in favour of the Buyers the Performance Bond issued by the SellersD Bank for 2% of the total value of the Contract in favour of the Buyers valid for 60 days from the date of opening of the L/C. The original of the said document should be dispatched to the Buyer's by courier mail. The copy of the AWB should be faxed to the Buyers immediately. E xxxxxxxx When failing to deliver the goods in time stipulated in clause 4 of the present Contract, the Sellers are to pay penalty to the Buyers at the rate of 0.3% of the value of F non-delivered Goods per each day of delay from the 5th day after expiry of the delivery date to the 15th day inclusive. Total amount of penalty should be paid to the Buyers within 10 days from the date of bill in the currency of the Contract. G 9. TERMS OF CANCELLATION OF THE CONTRACT The Buyers have the right to cancel the Contract under the following circumstances: The quality of the delivered Goods does not correspond to the Appendices No. 1 and No. 2 to H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1141 [R.M. LODHA, J.] the present Contract (according to the report of the A State Board Inspection of Russian Federation for the testing of the Goods at the port of shipment Kandla (India). The date of shipment of the Goods is postponed by the Sellers beyond the period of more than 15 B days.

The Sellers have the right to cancel the Contract if the date of the opening of the UC is postponed for the period of more than 15 days from the agreed date. c xxxxxxxx." 3. The buyers opened irrevocable letter of credit ('L/C') for the total value of the contract on December 3, 1997 with the last date of shipment- January 12, 1998. On presentation of documents by the sellers, the bank honoured UC and paid the . 0 amount to the sellers. The sellers shipped goods on January 29, 1998 - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of loading viz., Kandla (India) on February 20, 1998 - 38 days later than the time of departure stipulated in the contract. The goods never reached E the port of destination (port of Novorossiysk). It so happened that the vessel carrying the goods suffered an engine failure as a result of which it was declared 'General Average' by the Master of the vessel. In salvage operation, the vessel was rescued and taken to the Turkish sea port of Eregli. The owner of the rescue vessel claimed to the Admiralty Court of Eregli F to arrest the vessel with the cargo in an action for enforcement of the lien against the vessel. The concerned court took judgment to arrest vessel towards the cost of rescue and the entire cargo was sold out to compensate the cost of rescue of the vessel. G

4. The buyers lodged their claim with the United India Insurance Company Limited (insurers) on August 24, 1998 due to non-delivery of the goods to Novorossiysk. However, insurers denied their liability under the insurance policy for the loss of goods on the ground that risk of detention was not covered. H 1142 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A Their stand was that the insured voyage having been frustrated due to detention of the cargo, there was no liability under the policy. The sellers also took up the matter with the insurers and they were informed by the insurers vide letters dated September 16, 1998 and December 29, 1998 that the liability of the insurers was not established and the parties (the sellers and8 the buyers) must act as the goods were uninsured.

5. On November 27, 1998 the buyers lodged claim against the sellers for recovery of amount of USD 285,569.53 in the International Court of Commercial Arbitration at the Chamber c of Commerce and Industry of the Russian Federation (for short 'Arbitral Tribunal"). The buyers' claim was admitted for consideration by the Arbitral Tribunal on December 7, 1998. The sellers did not acknowledge the buyers' claim and set up the defences that they have honoured all commitments under D the contract; the risk in the goods and the property in the goods passed to the buyers upon shipment of the goods i.e. the date on which the goods were loaded on board the vessel being January 29, 1998 and in any event the property in the goods passed over to the buyers when their shipping documents were handed over through the banking channels upon negotiations E of the letter of credit, namely on February 19, 1998. According to the sellers, if for some reasons the goods were not received by the buyers then they had remedies under the policy of insurance against insurers or against the ship owners but in so far the sellers were concerned, they were not liable. The sellers F also set up the defence that the delayed shipment was acquiesced to and accepted by the buyers as they were informed of the delay of shipment; the buyers had right to repudiate the contract on the ground of delay in shipment which they never did. The sellers thus submitted before the Arbitral G Tribunal that the claim was misconceived and liable to be dismissed.

6. The Arbitral Tribunal held its sessions on various dates; heard the parties through their representatives and delivered its judgment (verdict) on October 18, 1999. The Arbitral Tribunal H did not find any merit in the defences set up by the sellers. It PHULCHAND EXPORTS LTD. v. 000 PATR!IOT 1143 [R.M. LODHA, J.]

held that the sellers broke the terms of the Contract (Article 4) A and shipped goods on January 29, 1998 - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of Kandla (India) on February 20, 1998 - 38 days later than the time of departure stipulated in the contract. The sellers gave a line bill of lading giving a carrier right to determine the line of 8 unloading and the consecutive order of destinalion of sea ports and, thus, at the moment of loading on board the vessel was no longer to reach the port of Novorossiysk as the first port of discharge in accordance with the terms of contract. The vessel with cargo had not arrived at the port of Novorossiysk on the date of lodging the claim (as a matter of fact the vessel never C reached the port of destination). The Arbitral Tribunal held that there was clear term about the commitment of the sellers to reimburse the paid amount towards goods in case of non-arrival. The Arbitral Tribunal referred to the sellers' conduct in sending its representatives to Eregli (Turkey) to find out the D situation of goods and observed that it was evident therefrom that the sellers did not consider themselves exempted from the commitment for fate and safety of the goods. It was held by the Arbitral Tribunal that the sellers did not prove the fact of force majeure which could discharge them from their liability. The E Arbitral Tribunal, however, found that there was delay on the part .· of the buyers in acting in accord with clause 4 of the Contract; they (buyers) did not pass the insurance certificate and cargo documents to the sellers and the buyers did not demand from the sellers reimbursement of the transferred amount immediately after expiration of 180 days (i.e. 26-27/11/1998). F The Arbitral Tribunal, therefore; split the amount of losses between the parties - buyers and sellers - in equal parts and ordered that the sellers shall pay the amount of USD 138,402.03 to the buyers. The Arbitral Tribunal awarded interest in the some of USD 2,562.71 payable by sellers to the buyers G and also directed the sellers to pay the amount of USD 4,869.00 to recover claimanfs expenses to pay registry and arbitrage fees.

7. The buyers filed Arbitration Petition on December 22, H 1144 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A 2000 before the High Court of Judicature at Bombay under Sections 47 and 48 of the Arbitration and Conciliation Act 1996 (hereinafter referred to as 'the 1996 Act') for enforcement of the above award. 8. The sellers contested the petition on the ground that B subject award was contrary to the principles of public policy and, therefore, the award was unenforceable. 9. The Single Judge of the Bombay High Court in his order dated July 16, 2001 did not find any merit in the objections raised by sellers; overruled the objections and held that the C award dated October 18, 1999 could be enforced as a decree of the Court. 10. Against the order of the Single Judge, the sellers preferred appeal before the Division Bench. The Division D Bench relying upon the decision of this Court in Renusagar Power Co. Ltd vs. General Electric Co'. held that award was purely based on findings of facts and no public policy was involved and the Single Judge rightly dismissed the petition. Consequently, the Division Bench by its order dated May 3, 2002 dismissed the appeal.

E 11. Mr. Krishnan Venugopal, learned Senior counsel for the appellant at the outset submitted that test concerning public policy applied by the Division Bench based on the decision of this Court in Renusagar Power Co. Ltcfl. is flawed. He referred to a subsequent decision of this Court in Oil and Natural Gas F Corporation Ltd. vs. Saw Pipes LtcP. and submitted that this Court has given wider meaning to the expression "public policy of India" used in Section 34 of the 1996 Act in that case. He submitted that the wider meanir.g given to the expression "public policy of India" used in Section 34 by this Court has also G been applied to the same expression occurring in Section 48 (2)(b) of the 1996 Act. He, thus, submitted that the matter needs to be sent back to the High Court for reconsideration on this ground alone. 1. AIR 1994 SC 860. H 2. (2003) 5 sec 10s PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1145 [R.M. LODHA, J.]

12. It is true that in Renusagar1, relied upon by the Division A Bench, a narrower meaning has been given to the expression 'public policy of India' while this Court in a subsequent decision in the case of Saw Pipes Ltd.2 has given wider meaning to that expression. This Court in the case of Saw Pipes Ltd.2 (para 31, page 727) stated as under: B "31. Therefore, in our view, the phrase "public policy of India" used in Section 34 in context is required to be given a wider meaning. It can be stated that the concept of public policy connotes some matter which concerns public good and the public interest. What is for public good or in public c · interest or what would be injurious or harmful to the public good or public interest has varied from time to time. However, the award which is, on the face of it, patently in violation of statutory provisions cannot be said to be in public interest. Such award/judgment/decision is likely to 0 adversely affect the administration of justice. Hence, in our view in addition to narrower meaning given to the term "public policy" in Renusagar case it is required to be held that the award could be set aside if it is patently illegal. The result would be - award could be set aside if it is contrary to: E (a) fundamental policy of Indian law; or (b) the interest of India; or (c) justice or morality, or

(d) in addition, if it is patently illegal. F Illegality must go to the root of the matter and if the illegality is of trivial nature it cannot be held that award is against the public policy. Award could also be set aside if it is so unfair and unreasonable that it shocks the conscience of the court. Such award is opposed to public policy and is G required to be adjudged void." 13. There is merit in the submission of learned senior counsel that in view of the decision of this Court in Saw Pipes Ltd.2, the expression 'public policy of India' used in Section 48 H (2)(b) has to be giv_en wider meaning and the award could be 1146 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A set aside, 'if it is patently illegal'. At the first blush we thought of remanding the matter to the High Court, but on a deeper thought, we decided to hear the objections relating to patent illegality in the award ourselves as the award by the Arbitral Tribunal was given as far back as on October 18, 1999 and B about 12 years have elapsed since then. We thought that the issue relating to enforceability of the subject award must be brought to an end finally one way or the other.

14. Mr. Krishnan Venugopal, learned Senior counsel strenuously urged that the contract entered into between the C sellers and the buyers was a CIF contract and the risk in the goods and the property passed over to the buyers upon the shipment of the goods on January 29, 1998 and in any case the property in the goods passed over to the buyers when the shipping documents were handed over to them through the D Banking channels on negotiations of letter of credit on February 19, 1998. He would submit that from this day the sellers' liabilities ceased to exist. In this connection he relied upon a decision of this Court in Mau/a Bux vs. Union of lndia3• He also referred to Section 26 of the Sale of Goods Act, 1930 (for short E '1930 Act').

15. Learned Senior counsel also submitted that the stipulation in clause 4, "in case the goods don't arrive the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to F the Buyers' account" amounts to penalty within the meaning of Section 74 of the Contract Act, 1872 (for short, '1872 Act') and being unconscionable bargain is void under Section 23 of the 1872 Act and, therefore, enforcement of the subject award by the Indian Courts is contrary to 'public policy of India'. He relied upon two decisions of House of Lords; (i) Lord Elphinstone vs. G The Monk/and Iron and Coal Company Limited, and Liquidafr,Jr$4; and (ii) Dunlop Pneumatic Tyre Company Limited vs. New Garage and Motor Company Limitecf'. 3. 1969 (2) sec 554. 4. 1.886 House of Lords VOL. XI page 332. H 5. (1915) AC 79. PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1147 [R.M. LODHA, J.) 16. C.1.F. (Cost, Insurance, Freight) contract is well- A understood by the people in commerce and in law. In Kennedy's C.1.F. Contracts (Third Edition) revised by Dennis C. Thompson, a C.l.F. contract is explained (at page 1) thus : " ......... It is a contract which contemplates the carriage of goods by sea, and is the most common form of shipping B contract in use today. It is known as a c.i.f. contract, for the price which the buyer has to pay is the cost of the goods, together with the insurance of the goods during transit and the freight to the port of destination.

Under this form of contract the seller performs his C obligations by shipping, at the time specified in the contract or, in default of express provision in the contract, within a reasonable time, goods of the contractual description in a ship bound for the destination named in the contract, or by purchasing documents in respect of such goods already D afloat, and by tendering to the buyer, as soon as possible after the goods have been destined to him, the shipping documents, i.e., a bill of lading for carriage of goods, a policy of insurance covering the reasonable value of the goods, together with an invoice showing the amount due E from the buyer." 17. In C.l.F. and F.O.B. Contracts (Fourth Edition) by David M. Sassoon dealing with essence of C.l.F. contracts, it is stated that essential feature of a C.l.F. contract is that delivery is satisfied by delivery of documents and not by actual physical F delivery of the goods. Shipping documents required under a C.1.F. contract are bill of lading, policy of insurance and an invoice. 18. In Johnson v. Taylor Bros. 6, Lord Atkinson in the House of Lords explained the meaning of C.l.F. contract as G under: " ....... when a vendor and purchaser of goods situated as they were in this case (Seller in Sweden and buyers in 6. [1920] A.C. 144 at p. 155. H 1148 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A England) enter into a c.i.f. contract, such as that entered into in the present case, (Ordinary c.i.f. terms), the vendor in the absence of any special prov;sion to the contrary is bound by his contract to do six things. First, to make out an invoice of the goods sold. Second, to ship at the port of shipment goods of the description contained in theB contract. Third, to procure (There might be added the words "on shipment, .see ante, § 7") a contract of affreightment under which the goods will be delivered at the destination contemplated by the contract. Fourth, to arrange for an insurance upon the terms current in thec trade which will be available for the benefit of the buyer. Fifthly, with all reasonable despatch to send forward and tender to the buyer these shipping documents, namely, the invoice, bill of lading and policy of assurance, delivery of which to the buyer is symbolical of delivery of the goods D purchased, placing the same at the buyer's risk and entitling the seller to payment of their price ....... .". 19. Section 26 of the 1930 Act upon which reliance was placed by the learned senior counsel for the sellers reads as follows: E "S. 26. Risk prima facie passes with property.- Unless otherwise agreed, the goods remain at the seller's risk until the property therein is transferred to the buyer, but when the property therein is transferred to the buyer, the goods are at the buyer's risk whether delivery has been F made or not:

Provided that, where delivery has been delayed through the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault: G Provided also that nothing in this section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the other party." 20. The title of Section 26 shows that the rule provided H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1149 [R.M. LODHA, J.]

there-under is the prima facie rule subject to the agreement A otherwise between the parties. This is clearly indicated by the expression "unless otherwise agreed" with which the section begins. The parties to the contract are, thus, free to by-pass the prima facie rule provided in Section 26 by making agreement otherwise. The prima facie rule in Section 26 is that B the goods remain at the seller's risk until the property in the goods is transferred to the buyer. But when the property in the goods is transferred to the buyer the goods are at the buyer's risk whether delivery has been made or not. The above rule has some exceptions. The first proviso provides that where delivery c of goods has been delayed due to the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault. The second proviso is further subject to the first proviso and provides that nothing in the section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the D other party.

21. The obligations upon a seller under a C.l.F. contract are well known, some of which are in relation to goods and some of which are in relation to documents. In relation to goods, the E seller must ship goods of contract description on board a ship bound to the contract destination. If there is a late shipment or the seller has put goods on board a ship not bound to the contract destination as stipulated, in our view, the logical inference that must necessarily follow is that the seller has not put on board goods conforming to a contract destination. F 22. In the present case, as we see it, there is late shipment· of goods by 16 days. Besides delay in shipping the goods and the delayed departure of the vessel from the port of loading, the goods were shipped in a vessel having no firm commitment to reach the port of Novorossiysk as the first port of discharge. G As a matter of fact the sellers gave a line bill of lading giving a carrier right to determine the line of unloading and the consecutive order of destination of sea ports and as a result of that the goods were loaded on board the vessel that was no longer to reach the port of Novorossiysk as first port of H 1150 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A discharge. The contract clearly provides in clause 4 that shipment should be done by a vessel that is on way to Novorossiysk as the first port of discharge. This term in the contract is not inconsequential or immaterial but seems to be fundamental having regard to the subject matter of the goods. The sellers breached the terms of the contract at the very8 threshold by late shipment of goods and by loading on board the vessel which was no. longer to reach the port of Novorossiysk as the first port of discharge. The sellers having breached the terms of the C.l.F. contract at the threshold, it is very difficult to hold that property in the goods got transferred out and out to C the buyers on shipment of the goods or when the shipping documents were handed over to the bank for negotiations of UC. In a case such as this one, the sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods can be held to have resulted in postponement of D transfer of title in goods to the buyers. In any case the prima facie rule contemplated in Section 26 of the 1930 Act stands rebutted in the facts of the present case.

23. Even if the property in the goods is deemed to have transferred to the buyers, since there was no delivery of the E goods due to the fault of the sellers in shipment of the goods, firstly belatedly and then by a vessel that was not on way to Novorossiysk as the first port of discharge, the goods continued to be at the risk of the sellers as they were in fault. In that situation, first proviso to Section 26 of the 1930 Act is clearly F attracted. 24. We do not find any merit in the case set up by the sellers that their liability ceased to exist on shipment of the goods on January 29, 1998 or in any case when the shipping documents were handed over through the banking channels on G negotiations of Letter of Credit. As in the present case, the sellers were in breach at the threshold, it is immaterial whether or not the buyers had a right of action against the insurers or carrier. 25. The buyers' claim was founded on the breach of H contract by the sellers and particularly with reference to the last PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1151 [R.M. LODHA, J.]

paragraph of clause 4 of the contract that provided, "in case A the goods do not arrive to the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the buyers' account". The goods not only did not arrive to the customs area of Russian Federation within 180 days from the date of payment but they 8 never arrived at all in the customs area of Russian Federation/ the port of Novorossiysk (port of discharge). The Arbitral Tribunal held that there were breaches by the sellers and that the above . clause for reimbursement could be invoked by the buyers. The Arbitral Tribunal, however, did not award the full price paid by C the buyers to the sellers but instead awarded half of that amount as there was delay by the buyers in invoking the clause of reimbursement and the buyers also did not pass the shipping documents and the insurance certificate to the sellers. The contention of the learned senior counsel for the sellers in contesting the enforcement of the award is that the clause of D reimbursement amounts to 'penalty' within the meaning of Section 74 of the 1872 Act and also unconscionable bargain and, therefore, void under Section 23 of that Act. He would, thus, submit that enforcement of such award would be contrary to public policy of India. E

26. Section 73 of the 1872 Act provides for compensation for loss or damage caused by breach of contract and Section 74 makes a provision for compensation for breach of contract where penalty is stipulated for. These two Sections - 73 and 74 - of the 1872 Act read as under: F "73. Compensation for loss or damage caused by breach of contract.- When a contract has been broken, the party who suffers by such breach is entitled to receive, from the party who has broken the contract, compensation for any loss or damage caused to him thereby, which naturally G arose in the usual course of things from such breach, or which the parties knew, when they made the contract, to be likely to result from the breach of it. Such compensation is not to be given for any remote and indirect loss or damage sustained by reason of the breach. H 1152 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A Compensation for failure to discharge obligation resembling those created by contract-When an obligation resembling those created by contract has been incurred and has not been discharged, any person injured by the failure to discharge it is entitled to receive the same compensation from the party in default, as if such personB had contracted to discharge it and had broken his contract. Explanation.-ln estimating the loss or damage arising from a breach of contract, the means which existed of remedying the inconvenience caused by the non-c performance of the contract must be taken into account. S. 74. Compensation for breach of contract where penalty stipulated for.-When a contract has been broken, if a sum is named in the contract as the amount to be paid in case of such breach, or if the contract contains any other D stipulation by way of penalty, the party complaining of the breach is entitled, whether or not actual damage or loss is proved to have been caused thereby, to receive from the party who has broken the contract reasonable compensation not exceeding the amount so named or, as the case may be, the penalty stipulated for.E Explanation.-· A stipulation for increased interest from the date of default may be a stipulation by way of penalty. Exception.- When any person enters into any bail-bond, recognizance or other instrument of the same nature, or F under the provisions of any law, or under the orders of the Central Government or of any State Government, gives any bond for the performance of any public duty or act in which the public are interested, he shall be liable, upon breach of the condition of any such instrument, to pay the whole G sum mentioned therein.

Explanation.- A person who enters into a contract with Government does not necessarily thereby undertake any public duty, or promise to do an act in which the public are . interested." H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1153 [R.M. LODHA, J.] 27. Both these Sections provide for reasonable A compensation in a case of breach of contract. None of these two Sections makes the award of liquidated damages illegal. Section 74, as observed by this Court, in the case of Fateh Chand v. Balkishan Dass7 is, "an attempt to eliminate the somewhat elaborate refinements made under the English 8 common law in distinguishing between stipulations providing for payment of liquidated damages and stipulations in the nature of penalty ......... The Indian Legislature has sought to cut across the web of rules and presumptions under the English common law, by enacting a uniform principle applicable to all C stipulations naming amounts to be paid in case of breach, and stipulations by way of penalty." 28. The plain reading of Section 74 would show that it deals with the measure of damages in two classes of cases (i) where the contract names a sum to be paid in case of breach and (ii) where the contract contains any other stipulation by way D of penalty. In Fateh Chand?, this Court held :

" .... The expression "if the contract contains any other stipulation by way of penalty" widens the operation of the section so as to make it applicable to all stipulations by E way of penalty, whether the stipulation is to pay an amount bf money, or is of another character, as, for example, providing for forfeiture of money already paid. There is nothing in the expression which implies that the stipulation must be one for rendering something after the contract is F broken. There is no ground for holding that the expression "contract contains any other stipulation by way of penalty" is limited to cases of stipulation in the nature of an agreement to pay money or deliver property on breach and does not comprehend covenants under which amounts paid or property delivered under the contract, which by the G terms of the contract expressly or by clear implication are liable to be forfeited." 29. In the case of Mauia Bux3 while dealing with Section 7. (1964) 1 SCR 515. H 1154 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A 74 of the 1872 Act, this Courtwas concerned with the case of forfeiture of the amount of deposit. It was held, "forfeiture of reasonable amount paid as earnest money does not amount to imposing a penalty. But, if forfeiture is of the nature of penalty, Section 74 applies". It was further held, 'where under the terms of the contract, the party in breach has undertaken to pay a sum8 of money or to forfeit a sum of money which he has already paid to the party complaining of a breach of contract, the undertaking 1is of the nature of a penalty'. We are afraid the decision of this Court in Maula Bux3 does not support the contention of the learned senior counsel that the stipulation of reimbursement C contained in last para of clause 4 of the contract to transfer the payment of goods already received by sellers in the event of non-delivery of the goods within 180 days in the customs area of Russian Federation amounts to penalty. The stipulation for reimbursement in the event stated in last para of clause 4 of D the contract is not in the nature of penalty; the clause is not in terrorem. It is neither punitive nor vindictive. Moreover, what has been provided in the contract is the reimbursement of the price of the goods paid by the buyers to the sellers. The clause of reimbursement or repayment in the event of delayed delivery/ E arrival or non-delivery is not to be regarded as damages. Even in the absence of such clause, where the seller has breached his obligations at threshold, the buyer is entitled to the return of the price paid and for damages. We can see no reason why the sellers should not be bound by it and the court should not F enforce such term. No way the clause is in the nature of threat held over the sellers in terror.

30. Section 23 of the 1872 Act reads as under : . "S. 23. What considerations and objects are lawful, and what not.-The consideration or object of an agreement G is lawful, unless- it is forbidden by law; or is of such a nature that, if permitted, it would defeat the provisions of any law; or H is fraudulent; or PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1155 [R.M. LODHA, J.] involves or implies injury to the person or property of A another; or the Court regards it as immoral, or opposed to public policy. In each ot these cases, the consideration or object of an 8 agreement is said to be unlawful. Every agreement of which the object or consideration is unlawful is void."

31. The transactions covered by Section 23 are the transactions where the consideration or object of such transaction is forbidden by law or the transaction is of such a c nature that if permitted would defeat the provisions of any law or the transaction is fraudulent or the transaction involves or implies injury to the person or property of another or where the court regards it immoral or opposed to public policy. Whether particular transaction is contrary to a public policy would 0ordinarily depend upon the nature of transaction. Where experienced businessmen are involved in a commercial contract and the parties are not of unequal bargaining power, the agreed terms must ordinarily be respected as the parties may be taken to have had regard to the matters known to them. The sellers and the buyers in the present case are business E persons having no unequal bargaining powers. They agreed on all terms of the contract being in conformity with the international trade and commerce. Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein is neither unreasonable nor F unjust; far from being extravagant or unconscionable. It is the precise sum which the sellers are required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time. More so, the fact of the matter is that goods never arrived at the port of G discharge. The Arbitral Tribunal has only awarded reimbursement of half the price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary tci the public policy of India.

H 1156 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A 32. Mr. Krishnan Venugopal, learned senior counsel would submit that the goods were insured and the buyers were made beneficiaries in the insurance policy and, therefore, they have right to claim loss for goods from the insurance company and not the sellers. Moreover, the right to claim under insurance B policy is not subrogated in favour of the buyers. The argument is noted to be rejected having no merit at all for the reasons already indicated above. 33. In view of the above there is no merit in the appeal and it is dismissed accordingly. Since the buyers (respondent) have c not chosen to appear, there shall be no order as to costs. B.B.B. Appeal dismissed.

[2011] 15 (ADDL.) S.C.R 1129 PHULCHAND EXPORTS LTD. A v. 000 PATRIOT (CIVIL APPEAL NO. 3343 OF 2005) OCTOBER 12, 2011 B [R.M. LODHA AND JAGDISH SINGH KHEHAR, JJ.]

Arbitration and Conciliation Act, 1996 - ss.47 and 48 -Enforcement of award - Test of principles of public policy -C/F Contract - The appellant-sellers shipped goods and the c vessel freighted by the sellers left the port of loading viz. Kand/a, India - The vessel carrying the goods, however, suffered engine failure and consequently the goods did not reach the port of destination (port of Novorossiysk, Russia) -The respondent-buyers lodged recovery claim against the 0sellers before the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of the Russian Federation, Moscow - The said Arbitral Tribunal held that there were breaches by the sellers and that the clause for reimbursement could be invoked by the buyers -The Arbitral Tribunal, however, did not award the full price paid E by the buyers to the sellers but instead awarded /Jalf of that amount as there was delay by the buyers in invoking the clause of reimbursement [clause 4 of the contract] and the buyers also did not pass the shipping documents and the insurance certificate to the sellers - Arbitration petition filed F by respondent-buyers for enforcement of the award - Allowed by High Court - Whether enforcement of the award in favour of the respondent was contrary to public policy of India under s.48(2)(b) of the Act - Held: The appellant-sellers breached the terms of the contract at the very threshold by late shipment G of goods and by loading on board the vessel which was no longer to reach the port of Novorossiysk as the first port of discharge - The sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods 1129 H

1130 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A can be held to have resulted in postponement of transfer of title in goods to the buyers - Even if the property in the goods was deemed to have transferred to the buyers, since there was no delivery of the goods due to the fault of the sellers in shipment of the goods, the goods continued to be at the risk B of the sellers - In that situation, first proviso to Section 26 of the 1930 Act was clearly attracted - No merit in the case set up by the sellers that their liability ceased to exist on shipment of the goods or in any case when the shipping documents were handed over through the banking channels on negotiations of Letter of Credit - Stipulation for C reimbursement in the event stated in clause 4 of the contract was not in the nature of penalty; the clause was not in terrorem

- It was neither punitive nor vindictive - No reason why the sellers should not be bound by it and the court should not enforce such term - The sellers and the buyers in the present D case were business persons having no unequal bargaining ppwers - Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein was neither unreasonable nor unjust; far from being extravagant or unconscionable - It was E the precise sum which the sellers were required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time -More so, the fact of the matter was that goods never arrived at the port of,discharge - The Arbitral Tribunal only awarded F reimbursement of half the· price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary to the public policy of India - Sale of Goods Act, 1930 - s.26 - Contract Act, 1872 - ss.23, 73 and 74. G Arbitration and Conciliation Act, 1996 - s.48(2)(b) -Expression 'public policy of India' used in s.48(2)(b) - Held: Has "to be given wider meaning - Arbitral award can be set aside, 'if it is patently illegal'.

Contract- CIF contract- Obligations upon a seller under H a C.J.F. contract - Held: In relation to goods, the seller must PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1131 ship goods of contract description on board a ship bound to A the contract destination - If there is a late shipment or the seller has put goods on board a ship not bound to the contract destination as stipulated, the logical inference that must necessarily follow is that the seller has not put on board goods conforming to a contract destination. B Transaction relating to sale of 1000 Metric Tons of Indian long grain polished rice for a price fixed at INR 12,450 (Indian Rupees twelve thousand four hundred fifty only) per one metric ton net on CIF (liner out) Novoross.iysk, Russia basis was concluded, vide a c contract between the appellant-sellers and respondent-buyers. The appellant-sellers shipped goods - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of loading viz., Kandla (India) - 38 days later than the time of departure stipulated in the contract. The goods, however, never reached the port of D destination (port of Novorossiysk) inasmuch as the vessel carrying the goods suffered an engine failure and in salvage operation, the vessel was taken to the Turkish sea port of Eregli where the concerned Admiralty court took judgment to arrest vessel towards the cost of rescue E and the entire cargo was sold out to compensate the cost of rescue of the vessel.

The respondent-buyers lodged claim against the sellers for recovery of amount in the International Court of Commercial Arbitration at the Chamber of Commerce F and Industry of the Russian Federation (for short "the Arbitral Tribunal"). The buyers' claim was founded on the breach of contract by the sellers and particularly with reference to clause 4 of the contract that provided, "in case the goods do not arrive to the customs area of G Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the buyers' account". The Arbitral Tribunal held that there were breaches by the sellers and that the clause for reimbursement H 1132 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A could be invoked by the buyers. The Arbitral Tribunal, however, did not award the full price paid by the buyers to the sellers but instead awarded half of that amount as there was delay by the buyers in invoking the clause of reimbursement and the buyers also did not pass the shipping documents and the insurance certificate to the 8 sellers. The buyers filed Arbitration Petition under Sections 47 and 48 of the Arbitration and Conciliation Act 1996 for enforcement of the above award. The sellers contested C the petition on the ground that subject award was contrary to the principles of public policy and, therefore, the award was unenforceable. A Single Judge of the High Court over-ruled the objections raised by sellers and held that the award could be enforced as a decree of the Court. The Division Bench relying upon the decision of D this Court in Renusagar Power held that award was purely based on findings of facts and no public policy was involved and upheld the order of the Single Judge. The question which arose for consideration in the E instant appeal was whether enforcement of the award given by the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of Russian Federation, Moscow in favour of the respondent was contrary to public policy of India under Section 48(2){b) of the Arbitration and Conciliation Act, 1996. F Dismissing the appeal, the Court HELD:1. In Renusagar Power case (as relied upon by the Division Bench of the High Court), a narrower meaning had been given to the expression 'public policy G of India' while this Court in a subsequent decision in the case of Saw Pipes Ltd. has given wider meaning to that expression. In view of the decision in Saw Pipes Ltd., the expression 'public policy of India' used in Section 48(2){b) has to be given wider meaning and the award could be H set aside, 'if it is patently illegal'. [Paras 12, 13] [1145-A-B: 1146-AJ

PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1133 Renusagar Power Co. Ltd vs. General Electric Co. AIR A 1994 SC 860: 1993 (3) Suppl. SCR 22; Oil and Natural Gas Corporation Ltd. vs. Saw Pipes Ltd. (2003) 5 SCC 705: 2003 (3) SCR 691 - referred to. 2.1. The title of Section 26 of the Sale of Goods Act, 1930 shows that the rule provided there-under is the B prima facie rule subject to the agreement otherwise between the parties. This is clearly indicated by the expression "unless otherwise agreed" with which the section begins. The parties to the contract are, thus, free to by-pass the prima facie rule provided in Section 26 by c making agreement otherwise. The prima facie rule in Section 26 is that the goods remain at the seller's risk until the property in the goods is transferred to the buyer. But when the property in the goods is transferred to the buyer the goods are at the buyer's risk whether delivery 0 has been made or not. The above rule has some exceptions. The first proviso provides that where delivery of goods has been delayed due to the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault. The second proviso is further subject E to the first proviso and provides that nothing in the section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the other party. [Para 20] [1148-H; 1149-A·D]

2.2. The obligations upon a seller under a C.l.F. F contract are well known, some of which are in relation to goods and some of which are in relation to documents. In relation to goods, the seller must ship goods of contract description on board a ship bound to the contract destination. If there is a late shipment or the G seller has put goods on board a ship not bound to the contract destination as stipulated, the logical Inference that must necessarily follow is that the seller has not put . on board goods conforming to a contract destination. [Para 21] [1149-E-F] H 1134 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A 2.3. In the present case, there was late shipment of goods by 16 days. Besides delay in shipping the goods and the delayed departure of the vessel from the port of loading, the goods were shipped in a vessel having no firm commitment to reach the port of Novorossiysk as the B first port of discharge. As a matter of fact, the sellers gave a line bill of lading giving a carrier right to determine the line of unloading ancf the consecutive order of '.lestinatioo "l>f sea ports and as a result of that the goods were loaded on board the vessel that was no longer to C reach the port of Novorossiysk as first port of discharge. The contract between the parties clearly provided in clause 4 that shipment should be done by a vessel that is on way to Novorossiysk as the first port of discharge. This term in the contract is not inconsequential or immaterial but seems to be fundamental having regard to D the subject matter of the goods. The sellers breached the terms of the contract at the very threshold by late shipment of goods and by loading on board the vessel which was no longer to reach the port of Novorossiysk as the first port of discharge. The sellers having breached E the terms of the C.1.F. contract at the threshold, it is very difficult to hold that property in the goods got transferred out and out to the buyers on shipment of the goods or when the shipping documents were handed over to the bank for negotiations of UC. In a case such as this one, F the sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods can be held to have resulted in postponement of transfer of title in goods to the buyers. In any case the prima facie rule contemplated in Section 26 of the 1930 Act stands rebutted in the facts of the present case. [Para 22) [1149· G G-H; 1150-A-D]

2.4. Even if the property in the goods is deemed to have transferred to the buyers, since there was no delivery of the goods due to the fault of the sellers in shipment of the goods, firstly belatedly and then by a H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1135 vessel that was not on way to Novorossiysk as the first A port of discharge, the goods continued to be at the risk of the sellers as they were in fault. In that situation, first proviso to Section 26 of the 1930 Act is clearly attracted. [Para 23] [1150-E-F] 2.5. There is no merit in the case set up by the sellers B that their liability ceased to exist on shipment of the goods or in any case when the shipping documents were handed over through the banking channels on negotiations of Letter of Credit. As in the present case, the sellers were in breach at the threshold, it is immaterial c whether or not the buyers had a right of action against the insurers or carrier. [Para 24] [1150-G] Johnson v. Taylor Bros. [1920] A.C. 144 - referred to. Lord Elphinstone vs. The Monk/and Iron and Coal Company Limited and Liquidators 1886 House of Lords D VOL. XI page 332 and Dunlop Pneumatic Tyre Company Limited vs. New Garage and Motor Company Limited (1915) AC 79 [House of Lords] - cited. Kennedy's CIF contracts (Third edition) revised by E Dennis C. Thompson and CIF and FOB Contracts (Fourth edition) by David M. Sassoon - referred to.

3.1. Section 73 of the Contract Act, 1872 provides for compensation for loss or damage caused by breach of contract and Section 74 makes a provision for F compensation for breach of contract where penalty is stipulated for. Both these Sections provide for reasonable compensation in a case of breach of contract. None of these two Sections makes the award of liquidated damages illegal. The plain reading of Section 74 would G show that it deals with the measure of damages in two classes of cases (i) where the contract names a sum to be paid in case of breach and (ii) where the contract contains any other stipulation by way of penalty. [Paras 26, 27 and 28] [1151-E-F; 1153-A-D] H 1136 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A 3.2. The stipulation for reimbursement in the event stated in clause 4 of the contract is not in the nature of penalty; the clause is not in terrorem. It is neither punitive nor vindictive. Moreover, what has been provided in the contract is the reimbursement of the price of the goods paid by the buyers to the sellers. The clause of8 reimbursement or repayment in the event of delayed delivery/arrival or non-delivery is not to be regarded as damages. Even in the absence of such clause, where the seller has breached his obligations at threshold, the buyer is entitled to the return of the price paid and for damages. C There is no reason why the sellers should not be bound by it and the court should not enforce such term. No way the clause is in the nature of threat held over the sellers in terror. [Para 29) [1154-B-E]

3.3. The transactions covered by Section 23 of the D 1872 Act are the transactions where the consideration or · object of such transaction is forbidden by law or the transaction is of such a nature that if permitted would defeat the provisions of any law or the transaction is fraudulent or the transaction involves or implies injury to E the person or property of another or where the court regards it immoral or opposed to public policy. Whether particular transaction is contrary to a public policy would ordinarily depend upon the nature of transaction. Where experienced businessmen are involved in a commercial F contract and the parties are not of unequal bargaining power, the agreed terms must ordinarily be respected as the parties may be taken to have had regard to the matters known to them. The sellers and the buyers in the present case are business persons having no unequal G bargaining powers. They agreed on all terms of the contract being in conformity with the international trade and commerce. Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein is neither unreasonable nor unjust; far from being extravagant or H

PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1137 unconscionable. It is the precise sum which the sellers A are required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time. More so, the fact of the matter is that goods never arrived at the port of discharge. The Arbitral Tribunal has only awarded B reimbursement of half the price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary to the public policy of India. [Para 31] [1155-C-H] Mau/a Bux vs. Union of India 1969 (2) SCC 554: 1970 c (1) SCR 928; Fateh Chand v. Balkishan Dass (1964) 1 SCR 515- referred to. Case Law Reference: 1993 (3) Suppl. SCR 22 referred to Paras 10,11, j2, D 2003 (3) SCR 691 referred to Para 11 1970 (1) SCR 928 referred to Para 14 1886 House of Lords VOL. Xlcited Para 15 (1915) AC 79 cited Para 15 E [1920] A.C. 144 referred to Para 18 (1964) 1 SCR 515 referred to Para 27 CIVIL APPELLATE JURISDICTION : Civil Appeal No. 3343 of 2005. . F From the Judgment & Order dated 3.5.2002 of the Bombay High Court in Appeal No. 4 of 2002 in Arbitration Petition No. 66 of 2001. Krishnan Venugopal, Kamal Budhiraja and Manu Seshadri G (for Dua Associates) for the Appellant. The Judgment of the Court was delivered by R.M. LODHA, J. 1. This appeal, by special leave, occupied judicial time of almost whole day, and the basic H

1138 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A question raised is this : whether enforcement of the award dated October 18, 1999 given by the International Court of Commercial Arbitration at the Chamber of Commerce and Industry of Russian Federation, Moscow in favour of the respondent is contrary to public policy of India under Section B 48(2)(b) of the Arbitration and Conciliation Act, 1996.

2. By contract dated November 18, 1997, between -Phulchand Exports Limited, Mumbai, India ('the sellers') and 000 Patriot, Moscow, Russia ('the buyers'), a transaction relating to sale of 1000 Metric Tons of Indian long grain 1.5 time c polished rice PR-106 of 9 per cent broken maximum (for short, 'the goods') for a price fixed at INR 12,450 (Indian Rupees twelve thousand four hundred fifty only) per one metric ton net on CIF (liner out) Novorossiysk, Russia basis was concluded. The price was fixed according to lncoterms-90 and included value of the goods, packing and marl<ing, loading into hold,0 stowing of the cargo, fulfilling the customs formalities in the sellers' country, insurance, freight charges, berthing charges and unloading charges of the goods at the port of Novorossiysk. The total value of the contract was firm and fixed at INR 12,450,000,00 (Indian Rupees twelve million four hundred fifty E thousand only). It is upon this contract, and on what was done under it, that the above question in this appeal turns. Some of the relevant terms, and, omitting clauses which do not appear important, are as follows : "1. SUBJECT OF CONTRACT : F ............. the Goods on CIF Novorossiysk port, Russia basis, ......... . 2. PRICE OF THE CONTRACT ......... The price is fixed on the terms of CIF (liner out) G Novorossiysk, Russia according to lncoterms-90 ........ . 3. TERMS OF PAYMENT

Payment for the Goods, delivered under the present contract is to be effected by irrevocable documentary H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1139 [R.M. LODHA, J.] Letter of Credit opened in favour of the sellers for the total A value of the contract for the period of 45 days ............ . The L/C is governed by "ICC Uniform customs and practice for documentary UC" .......... . The L/C should be opened within 10 working days from B the date of signing of the contract. The L/C is executed by the beneficiary's bank against presentation by the sellers of the following documents: xxxxxxxx 3. Insurance Policy for 11 % of the value of the Goods, C Covering all risks stipulated in the Institute Cargo Clauses (A), Institute War Clauses, Institute Strike Clauses till the completion of the unloading of !he Goods at the port of Novorossiysk, issued in the name of the Buyers Bank - Joint Stock Commercial D Bank AVTOBANK, Moscow, Russia. xxxxxxx 4. TERMS OF DELIVERY

Shipment should be done on the basis of CIF (liner out) E Novorossiysk, Russia in accordance with lncoterms - 90. The Goods sold under the present contract should be shipped within 40 days from the date of opening the UC. The date of shipment is the date of loading of the Goods F to the board of vessel. ............... . Shipment should be done by a vessel that is on the way to Novorossiysk as the first port of discharge. The Sellers shall take all possible measures that transit time of the Goods to Novorossiysk, Russia will not exceed 25 days. G xxxxxxxxx The sellers shall take all possible measures for placing the Goods in such a way that it will be free for examination and will not be blocked up by any other cargo while unloading at the port of Novorossiysk... ... . . . . H 1140 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A Insurance Policy for 110% of the value of the Goods, covering all risks, stipulated in the Institute Cargo Clauses (A), Institute War Clauses, Institute Strike Clauses till the completion of the unloading of the Goods at ~he port of Novorossiysk, issued in the name of the Buy~rs Bank -Joint Stock Commercial Bank AVTOBANK ......... .B xxxxxxxx In case the Goods do not arrive to the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the C Buyers' account. 8. PENALTY

The Sellers are obliged within 5 working days from the <;late of receipt of the Buyers advice of the UC to open in favour of the Buyers the Performance Bond issued by the SellersD Bank for 2% of the total value of the Contract in favour of the Buyers valid for 60 days from the date of opening of the L/C. The original of the said document should be dispatched to the Buyer's by courier mail. The copy of the AWB should be faxed to the Buyers immediately. E xxxxxxxx When failing to deliver the goods in time stipulated in clause 4 of the present Contract, the Sellers are to pay penalty to the Buyers at the rate of 0.3% of the value of F non-delivered Goods per each day of delay from the 5th day after expiry of the delivery date to the 15th day inclusive. Total amount of penalty should be paid to the Buyers within 10 days from the date of bill in the currency of the Contract. G 9. TERMS OF CANCELLATION OF THE CONTRACT The Buyers have the right to cancel the Contract under the following circumstances: The quality of the delivered Goods does not correspond to the Appendices No. 1 and No. 2 to H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1141 [R.M. LODHA, J.] the present Contract (according to the report of the A State Board Inspection of Russian Federation for the testing of the Goods at the port of shipment Kandla (India). The date of shipment of the Goods is postponed by the Sellers beyond the period of more than 15 B days.

The Sellers have the right to cancel the Contract if the date of the opening of the UC is postponed for the period of more than 15 days from the agreed date. c xxxxxxxx." 3. The buyers opened irrevocable letter of credit ('L/C') for the total value of the contract on December 3, 1997 with the last date of shipment- January 12, 1998. On presentation of documents by the sellers, the bank honoured UC and paid the . 0 amount to the sellers. The sellers shipped goods on January 29, 1998 - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of loading viz., Kandla (India) on February 20, 1998 - 38 days later than the time of departure stipulated in the contract. The goods never reached E the port of destination (port of Novorossiysk). It so happened that the vessel carrying the goods suffered an engine failure as a result of which it was declared 'General Average' by the Master of the vessel. In salvage operation, the vessel was rescued and taken to the Turkish sea port of Eregli. The owner of the rescue vessel claimed to the Admiralty Court of Eregli F to arrest the vessel with the cargo in an action for enforcement of the lien against the vessel. The concerned court took judgment to arrest vessel towards the cost of rescue and the entire cargo was sold out to compensate the cost of rescue of the vessel. G

4. The buyers lodged their claim with the United India Insurance Company Limited (insurers) on August 24, 1998 due to non-delivery of the goods to Novorossiysk. However, insurers denied their liability under the insurance policy for the loss of goods on the ground that risk of detention was not covered. H 1142 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A Their stand was that the insured voyage having been frustrated due to detention of the cargo, there was no liability under the policy. The sellers also took up the matter with the insurers and they were informed by the insurers vide letters dated September 16, 1998 and December 29, 1998 that the liability of the insurers was not established and the parties (the sellers and8 the buyers) must act as the goods were uninsured.

5. On November 27, 1998 the buyers lodged claim against the sellers for recovery of amount of USD 285,569.53 in the International Court of Commercial Arbitration at the Chamber c of Commerce and Industry of the Russian Federation (for short 'Arbitral Tribunal"). The buyers' claim was admitted for consideration by the Arbitral Tribunal on December 7, 1998. The sellers did not acknowledge the buyers' claim and set up the defences that they have honoured all commitments under D the contract; the risk in the goods and the property in the goods passed to the buyers upon shipment of the goods i.e. the date on which the goods were loaded on board the vessel being January 29, 1998 and in any event the property in the goods passed over to the buyers when their shipping documents were handed over through the banking channels upon negotiations E of the letter of credit, namely on February 19, 1998. According to the sellers, if for some reasons the goods were not received by the buyers then they had remedies under the policy of insurance against insurers or against the ship owners but in so far the sellers were concerned, they were not liable. The sellers F also set up the defence that the delayed shipment was acquiesced to and accepted by the buyers as they were informed of the delay of shipment; the buyers had right to repudiate the contract on the ground of delay in shipment which they never did. The sellers thus submitted before the Arbitral G Tribunal that the claim was misconceived and liable to be dismissed.

6. The Arbitral Tribunal held its sessions on various dates; heard the parties through their representatives and delivered its judgment (verdict) on October 18, 1999. The Arbitral Tribunal H did not find any merit in the defences set up by the sellers. It PHULCHAND EXPORTS LTD. v. 000 PATR!IOT 1143 [R.M. LODHA, J.]

held that the sellers broke the terms of the Contract (Article 4) A and shipped goods on January 29, 1998 - 16 days later of the stipulated time and the vessel freighted by the sellers left the port of Kandla (India) on February 20, 1998 - 38 days later than the time of departure stipulated in the contract. The sellers gave a line bill of lading giving a carrier right to determine the line of 8 unloading and the consecutive order of destinalion of sea ports and, thus, at the moment of loading on board the vessel was no longer to reach the port of Novorossiysk as the first port of discharge in accordance with the terms of contract. The vessel with cargo had not arrived at the port of Novorossiysk on the date of lodging the claim (as a matter of fact the vessel never C reached the port of destination). The Arbitral Tribunal held that there was clear term about the commitment of the sellers to reimburse the paid amount towards goods in case of non-arrival. The Arbitral Tribunal referred to the sellers' conduct in sending its representatives to Eregli (Turkey) to find out the D situation of goods and observed that it was evident therefrom that the sellers did not consider themselves exempted from the commitment for fate and safety of the goods. It was held by the Arbitral Tribunal that the sellers did not prove the fact of force majeure which could discharge them from their liability. The E Arbitral Tribunal, however, found that there was delay on the part .· of the buyers in acting in accord with clause 4 of the Contract; they (buyers) did not pass the insurance certificate and cargo documents to the sellers and the buyers did not demand from the sellers reimbursement of the transferred amount immediately after expiration of 180 days (i.e. 26-27/11/1998). F The Arbitral Tribunal, therefore; split the amount of losses between the parties - buyers and sellers - in equal parts and ordered that the sellers shall pay the amount of USD 138,402.03 to the buyers. The Arbitral Tribunal awarded interest in the some of USD 2,562.71 payable by sellers to the buyers G and also directed the sellers to pay the amount of USD 4,869.00 to recover claimanfs expenses to pay registry and arbitrage fees.

7. The buyers filed Arbitration Petition on December 22, H 1144 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A 2000 before the High Court of Judicature at Bombay under Sections 47 and 48 of the Arbitration and Conciliation Act 1996 (hereinafter referred to as 'the 1996 Act') for enforcement of the above award. 8. The sellers contested the petition on the ground that B subject award was contrary to the principles of public policy and, therefore, the award was unenforceable. 9. The Single Judge of the Bombay High Court in his order dated July 16, 2001 did not find any merit in the objections raised by sellers; overruled the objections and held that the C award dated October 18, 1999 could be enforced as a decree of the Court. 10. Against the order of the Single Judge, the sellers preferred appeal before the Division Bench. The Division D Bench relying upon the decision of this Court in Renusagar Power Co. Ltd vs. General Electric Co'. held that award was purely based on findings of facts and no public policy was involved and the Single Judge rightly dismissed the petition. Consequently, the Division Bench by its order dated May 3, 2002 dismissed the appeal.

E 11. Mr. Krishnan Venugopal, learned Senior counsel for the appellant at the outset submitted that test concerning public policy applied by the Division Bench based on the decision of this Court in Renusagar Power Co. Ltcfl. is flawed. He referred to a subsequent decision of this Court in Oil and Natural Gas F Corporation Ltd. vs. Saw Pipes LtcP. and submitted that this Court has given wider meaning to the expression "public policy of India" used in Section 34 of the 1996 Act in that case. He submitted that the wider meanir.g given to the expression "public policy of India" used in Section 34 by this Court has also G been applied to the same expression occurring in Section 48 (2)(b) of the 1996 Act. He, thus, submitted that the matter needs to be sent back to the High Court for reconsideration on this ground alone. 1. AIR 1994 SC 860. H 2. (2003) 5 sec 10s PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1145 [R.M. LODHA, J.]

12. It is true that in Renusagar1, relied upon by the Division A Bench, a narrower meaning has been given to the expression 'public policy of India' while this Court in a subsequent decision in the case of Saw Pipes Ltd.2 has given wider meaning to that expression. This Court in the case of Saw Pipes Ltd.2 (para 31, page 727) stated as under: B "31. Therefore, in our view, the phrase "public policy of India" used in Section 34 in context is required to be given a wider meaning. It can be stated that the concept of public policy connotes some matter which concerns public good and the public interest. What is for public good or in public c · interest or what would be injurious or harmful to the public good or public interest has varied from time to time. However, the award which is, on the face of it, patently in violation of statutory provisions cannot be said to be in public interest. Such award/judgment/decision is likely to 0 adversely affect the administration of justice. Hence, in our view in addition to narrower meaning given to the term "public policy" in Renusagar case it is required to be held that the award could be set aside if it is patently illegal. The result would be - award could be set aside if it is contrary to: E (a) fundamental policy of Indian law; or (b) the interest of India; or (c) justice or morality, or

(d) in addition, if it is patently illegal. F Illegality must go to the root of the matter and if the illegality is of trivial nature it cannot be held that award is against the public policy. Award could also be set aside if it is so unfair and unreasonable that it shocks the conscience of the court. Such award is opposed to public policy and is G required to be adjudged void." 13. There is merit in the submission of learned senior counsel that in view of the decision of this Court in Saw Pipes Ltd.2, the expression 'public policy of India' used in Section 48 H (2)(b) has to be giv_en wider meaning and the award could be 1146 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A set aside, 'if it is patently illegal'. At the first blush we thought of remanding the matter to the High Court, but on a deeper thought, we decided to hear the objections relating to patent illegality in the award ourselves as the award by the Arbitral Tribunal was given as far back as on October 18, 1999 and B about 12 years have elapsed since then. We thought that the issue relating to enforceability of the subject award must be brought to an end finally one way or the other.

14. Mr. Krishnan Venugopal, learned Senior counsel strenuously urged that the contract entered into between the C sellers and the buyers was a CIF contract and the risk in the goods and the property passed over to the buyers upon the shipment of the goods on January 29, 1998 and in any case the property in the goods passed over to the buyers when the shipping documents were handed over to them through the D Banking channels on negotiations of letter of credit on February 19, 1998. He would submit that from this day the sellers' liabilities ceased to exist. In this connection he relied upon a decision of this Court in Mau/a Bux vs. Union of lndia3• He also referred to Section 26 of the Sale of Goods Act, 1930 (for short E '1930 Act').

15. Learned Senior counsel also submitted that the stipulation in clause 4, "in case the goods don't arrive the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to F the Buyers' account" amounts to penalty within the meaning of Section 74 of the Contract Act, 1872 (for short, '1872 Act') and being unconscionable bargain is void under Section 23 of the 1872 Act and, therefore, enforcement of the subject award by the Indian Courts is contrary to 'public policy of India'. He relied upon two decisions of House of Lords; (i) Lord Elphinstone vs. G The Monk/and Iron and Coal Company Limited, and Liquidafr,Jr$4; and (ii) Dunlop Pneumatic Tyre Company Limited vs. New Garage and Motor Company Limitecf'. 3. 1969 (2) sec 554. 4. 1.886 House of Lords VOL. XI page 332. H 5. (1915) AC 79. PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1147 [R.M. LODHA, J.) 16. C.1.F. (Cost, Insurance, Freight) contract is well- A understood by the people in commerce and in law. In Kennedy's C.1.F. Contracts (Third Edition) revised by Dennis C. Thompson, a C.l.F. contract is explained (at page 1) thus : " ......... It is a contract which contemplates the carriage of goods by sea, and is the most common form of shipping B contract in use today. It is known as a c.i.f. contract, for the price which the buyer has to pay is the cost of the goods, together with the insurance of the goods during transit and the freight to the port of destination.

Under this form of contract the seller performs his C obligations by shipping, at the time specified in the contract or, in default of express provision in the contract, within a reasonable time, goods of the contractual description in a ship bound for the destination named in the contract, or by purchasing documents in respect of such goods already D afloat, and by tendering to the buyer, as soon as possible after the goods have been destined to him, the shipping documents, i.e., a bill of lading for carriage of goods, a policy of insurance covering the reasonable value of the goods, together with an invoice showing the amount due E from the buyer." 17. In C.l.F. and F.O.B. Contracts (Fourth Edition) by David M. Sassoon dealing with essence of C.l.F. contracts, it is stated that essential feature of a C.l.F. contract is that delivery is satisfied by delivery of documents and not by actual physical F delivery of the goods. Shipping documents required under a C.1.F. contract are bill of lading, policy of insurance and an invoice. 18. In Johnson v. Taylor Bros. 6, Lord Atkinson in the House of Lords explained the meaning of C.l.F. contract as G under: " ....... when a vendor and purchaser of goods situated as they were in this case (Seller in Sweden and buyers in 6. [1920] A.C. 144 at p. 155. H 1148 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A England) enter into a c.i.f. contract, such as that entered into in the present case, (Ordinary c.i.f. terms), the vendor in the absence of any special prov;sion to the contrary is bound by his contract to do six things. First, to make out an invoice of the goods sold. Second, to ship at the port of shipment goods of the description contained in theB contract. Third, to procure (There might be added the words "on shipment, .see ante, § 7") a contract of affreightment under which the goods will be delivered at the destination contemplated by the contract. Fourth, to arrange for an insurance upon the terms current in thec trade which will be available for the benefit of the buyer. Fifthly, with all reasonable despatch to send forward and tender to the buyer these shipping documents, namely, the invoice, bill of lading and policy of assurance, delivery of which to the buyer is symbolical of delivery of the goods D purchased, placing the same at the buyer's risk and entitling the seller to payment of their price ....... .". 19. Section 26 of the 1930 Act upon which reliance was placed by the learned senior counsel for the sellers reads as follows: E "S. 26. Risk prima facie passes with property.- Unless otherwise agreed, the goods remain at the seller's risk until the property therein is transferred to the buyer, but when the property therein is transferred to the buyer, the goods are at the buyer's risk whether delivery has been F made or not:

Provided that, where delivery has been delayed through the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault: G Provided also that nothing in this section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the other party." 20. The title of Section 26 shows that the rule provided H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1149 [R.M. LODHA, J.]

there-under is the prima facie rule subject to the agreement A otherwise between the parties. This is clearly indicated by the expression "unless otherwise agreed" with which the section begins. The parties to the contract are, thus, free to by-pass the prima facie rule provided in Section 26 by making agreement otherwise. The prima facie rule in Section 26 is that B the goods remain at the seller's risk until the property in the goods is transferred to the buyer. But when the property in the goods is transferred to the buyer the goods are at the buyer's risk whether delivery has been made or not. The above rule has some exceptions. The first proviso provides that where delivery c of goods has been delayed due to the fault of either buyer or seller, the goods are at the risk of the party in fault as regards any loss which might not have occurred but for such fault. The second proviso is further subject to the first proviso and provides that nothing in the section shall affect the duties or liabilities of either seller or buyer as bailee of the goods of the D other party.

21. The obligations upon a seller under a C.l.F. contract are well known, some of which are in relation to goods and some of which are in relation to documents. In relation to goods, the E seller must ship goods of contract description on board a ship bound to the contract destination. If there is a late shipment or the seller has put goods on board a ship not bound to the contract destination as stipulated, in our view, the logical inference that must necessarily follow is that the seller has not put on board goods conforming to a contract destination. F 22. In the present case, as we see it, there is late shipment· of goods by 16 days. Besides delay in shipping the goods and the delayed departure of the vessel from the port of loading, the goods were shipped in a vessel having no firm commitment to reach the port of Novorossiysk as the first port of discharge. G As a matter of fact the sellers gave a line bill of lading giving a carrier right to determine the line of unloading and the consecutive order of destination of sea ports and as a result of that the goods were loaded on board the vessel that was no longer to reach the port of Novorossiysk as first port of H 1150 SUPREME COURT REPORTS (2011] 15 (ADDL.) S.C.R.

A discharge. The contract clearly provides in clause 4 that shipment should be done by a vessel that is on way to Novorossiysk as the first port of discharge. This term in the contract is not inconsequential or immaterial but seems to be fundamental having regard to the subject matter of the goods. The sellers breached the terms of the contract at the very8 threshold by late shipment of goods and by loading on board the vessel which was no. longer to reach the port of Novorossiysk as the first port of discharge. The sellers having breached the terms of the C.l.F. contract at the threshold, it is very difficult to hold that property in the goods got transferred out and out to C the buyers on shipment of the goods or when the shipping documents were handed over to the bank for negotiations of UC. In a case such as this one, the sellers' failure to discharge the primary obligation under the contract regarding the shipment of goods can be held to have resulted in postponement of D transfer of title in goods to the buyers. In any case the prima facie rule contemplated in Section 26 of the 1930 Act stands rebutted in the facts of the present case.

23. Even if the property in the goods is deemed to have transferred to the buyers, since there was no delivery of the E goods due to the fault of the sellers in shipment of the goods, firstly belatedly and then by a vessel that was not on way to Novorossiysk as the first port of discharge, the goods continued to be at the risk of the sellers as they were in fault. In that situation, first proviso to Section 26 of the 1930 Act is clearly F attracted. 24. We do not find any merit in the case set up by the sellers that their liability ceased to exist on shipment of the goods on January 29, 1998 or in any case when the shipping documents were handed over through the banking channels on G negotiations of Letter of Credit. As in the present case, the sellers were in breach at the threshold, it is immaterial whether or not the buyers had a right of action against the insurers or carrier. 25. The buyers' claim was founded on the breach of H contract by the sellers and particularly with reference to the last PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1151 [R.M. LODHA, J.]

paragraph of clause 4 of the contract that provided, "in case A the goods do not arrive to the customs area of Russian Federation within 180 days from the date of payment the transferred amount is to be reimbursed to the buyers' account". The goods not only did not arrive to the customs area of Russian Federation within 180 days from the date of payment but they 8 never arrived at all in the customs area of Russian Federation/ the port of Novorossiysk (port of discharge). The Arbitral Tribunal held that there were breaches by the sellers and that the above . clause for reimbursement could be invoked by the buyers. The Arbitral Tribunal, however, did not award the full price paid by C the buyers to the sellers but instead awarded half of that amount as there was delay by the buyers in invoking the clause of reimbursement and the buyers also did not pass the shipping documents and the insurance certificate to the sellers. The contention of the learned senior counsel for the sellers in contesting the enforcement of the award is that the clause of D reimbursement amounts to 'penalty' within the meaning of Section 74 of the 1872 Act and also unconscionable bargain and, therefore, void under Section 23 of that Act. He would, thus, submit that enforcement of such award would be contrary to public policy of India. E

26. Section 73 of the 1872 Act provides for compensation for loss or damage caused by breach of contract and Section 74 makes a provision for compensation for breach of contract where penalty is stipulated for. These two Sections - 73 and 74 - of the 1872 Act read as under: F "73. Compensation for loss or damage caused by breach of contract.- When a contract has been broken, the party who suffers by such breach is entitled to receive, from the party who has broken the contract, compensation for any loss or damage caused to him thereby, which naturally G arose in the usual course of things from such breach, or which the parties knew, when they made the contract, to be likely to result from the breach of it. Such compensation is not to be given for any remote and indirect loss or damage sustained by reason of the breach. H 1152 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A Compensation for failure to discharge obligation resembling those created by contract-When an obligation resembling those created by contract has been incurred and has not been discharged, any person injured by the failure to discharge it is entitled to receive the same compensation from the party in default, as if such personB had contracted to discharge it and had broken his contract. Explanation.-ln estimating the loss or damage arising from a breach of contract, the means which existed of remedying the inconvenience caused by the non-c performance of the contract must be taken into account. S. 74. Compensation for breach of contract where penalty stipulated for.-When a contract has been broken, if a sum is named in the contract as the amount to be paid in case of such breach, or if the contract contains any other D stipulation by way of penalty, the party complaining of the breach is entitled, whether or not actual damage or loss is proved to have been caused thereby, to receive from the party who has broken the contract reasonable compensation not exceeding the amount so named or, as the case may be, the penalty stipulated for.E Explanation.-· A stipulation for increased interest from the date of default may be a stipulation by way of penalty. Exception.- When any person enters into any bail-bond, recognizance or other instrument of the same nature, or F under the provisions of any law, or under the orders of the Central Government or of any State Government, gives any bond for the performance of any public duty or act in which the public are interested, he shall be liable, upon breach of the condition of any such instrument, to pay the whole G sum mentioned therein.

Explanation.- A person who enters into a contract with Government does not necessarily thereby undertake any public duty, or promise to do an act in which the public are . interested." H PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1153 [R.M. LODHA, J.] 27. Both these Sections provide for reasonable A compensation in a case of breach of contract. None of these two Sections makes the award of liquidated damages illegal. Section 74, as observed by this Court, in the case of Fateh Chand v. Balkishan Dass7 is, "an attempt to eliminate the somewhat elaborate refinements made under the English 8 common law in distinguishing between stipulations providing for payment of liquidated damages and stipulations in the nature of penalty ......... The Indian Legislature has sought to cut across the web of rules and presumptions under the English common law, by enacting a uniform principle applicable to all C stipulations naming amounts to be paid in case of breach, and stipulations by way of penalty." 28. The plain reading of Section 74 would show that it deals with the measure of damages in two classes of cases (i) where the contract names a sum to be paid in case of breach and (ii) where the contract contains any other stipulation by way D of penalty. In Fateh Chand?, this Court held :

" .... The expression "if the contract contains any other stipulation by way of penalty" widens the operation of the section so as to make it applicable to all stipulations by E way of penalty, whether the stipulation is to pay an amount bf money, or is of another character, as, for example, providing for forfeiture of money already paid. There is nothing in the expression which implies that the stipulation must be one for rendering something after the contract is F broken. There is no ground for holding that the expression "contract contains any other stipulation by way of penalty" is limited to cases of stipulation in the nature of an agreement to pay money or deliver property on breach and does not comprehend covenants under which amounts paid or property delivered under the contract, which by the G terms of the contract expressly or by clear implication are liable to be forfeited." 29. In the case of Mauia Bux3 while dealing with Section 7. (1964) 1 SCR 515. H 1154 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R.

A 74 of the 1872 Act, this Courtwas concerned with the case of forfeiture of the amount of deposit. It was held, "forfeiture of reasonable amount paid as earnest money does not amount to imposing a penalty. But, if forfeiture is of the nature of penalty, Section 74 applies". It was further held, 'where under the terms of the contract, the party in breach has undertaken to pay a sum8 of money or to forfeit a sum of money which he has already paid to the party complaining of a breach of contract, the undertaking 1is of the nature of a penalty'. We are afraid the decision of this Court in Maula Bux3 does not support the contention of the learned senior counsel that the stipulation of reimbursement C contained in last para of clause 4 of the contract to transfer the payment of goods already received by sellers in the event of non-delivery of the goods within 180 days in the customs area of Russian Federation amounts to penalty. The stipulation for reimbursement in the event stated in last para of clause 4 of D the contract is not in the nature of penalty; the clause is not in terrorem. It is neither punitive nor vindictive. Moreover, what has been provided in the contract is the reimbursement of the price of the goods paid by the buyers to the sellers. The clause of reimbursement or repayment in the event of delayed delivery/ E arrival or non-delivery is not to be regarded as damages. Even in the absence of such clause, where the seller has breached his obligations at threshold, the buyer is entitled to the return of the price paid and for damages. We can see no reason why the sellers should not be bound by it and the court should not F enforce such term. No way the clause is in the nature of threat held over the sellers in terror.

30. Section 23 of the 1872 Act reads as under : . "S. 23. What considerations and objects are lawful, and what not.-The consideration or object of an agreement G is lawful, unless- it is forbidden by law; or is of such a nature that, if permitted, it would defeat the provisions of any law; or H is fraudulent; or PHULCHAND EXPORTS LTD. v. 000 PATRIOT 1155 [R.M. LODHA, J.] involves or implies injury to the person or property of A another; or the Court regards it as immoral, or opposed to public policy. In each ot these cases, the consideration or object of an 8 agreement is said to be unlawful. Every agreement of which the object or consideration is unlawful is void."

31. The transactions covered by Section 23 are the transactions where the consideration or object of such transaction is forbidden by law or the transaction is of such a c nature that if permitted would defeat the provisions of any law or the transaction is fraudulent or the transaction involves or implies injury to the person or property of another or where the court regards it immoral or opposed to public policy. Whether particular transaction is contrary to a public policy would 0ordinarily depend upon the nature of transaction. Where experienced businessmen are involved in a commercial contract and the parties are not of unequal bargaining power, the agreed terms must ordinarily be respected as the parties may be taken to have had regard to the matters known to them. The sellers and the buyers in the present case are business E persons having no unequal bargaining powers. They agreed on all terms of the contract being in conformity with the international trade and commerce. Having regard to the subject matter of the contract, the clause for reimbursement or repayment in the circumstances provided therein is neither unreasonable nor F unjust; far from being extravagant or unconscionable. It is the precise sum which the sellers are required to reimburse to the buyers, which they had received for the goods, in case of the non-arrival of the goods within the prescribed time. More so, the fact of the matter is that goods never arrived at the port of G discharge. The Arbitral Tribunal has only awarded reimbursement of half the price paid by the buyers to the sellers and, therefore, the award cannot be held to be unjust, unreasonable or unconscionable or contrary tci the public policy of India.

H 1156 SUPREME COURT REPORTS [2011] 15 (ADDL.) S.C.R. A 32. Mr. Krishnan Venugopal, learned senior counsel would submit that the goods were insured and the buyers were made beneficiaries in the insurance policy and, therefore, they have right to claim loss for goods from the insurance company and not the sellers. Moreover, the right to claim under insurance B policy is not subrogated in favour of the buyers. The argument is noted to be rejected having no merit at all for the reasons already indicated above. 33. In view of the above there is no merit in the appeal and it is dismissed accordingly. Since the buyers (respondent) have c not chosen to appear, there shall be no order as to costs. B.B.B. Appeal dismissed.